Introduction
Construction Manager as Constructor (CMc) may be used with specific, prior written concurrence from USDA-Rural Development (RD). Concurrence will be provided in accordance with the Administrative Notice titled “Design/Build and Construction Management Proposal for Community Facilities Projects”.
All contracting method projects must comply with the RD requirements for “maximum open and free competition.” All procurement transactions, regardless of whether by sealed bids or by negotiation, and without regard to dollar value, shall be conducted in a manner that provides maximum open and free competition. Procurement procedures shall not restrict or eliminate competition. Examples of what are considered to be restrictive of competition include, but are not limited to: placing unreasonable requirements on firms in order for them to qualify to do business, using location of the firm in the selection criteria, noncompetitive practices between firms, organizational conflicts of interest and unnecessary experience and bonding requirements.
RD has specific documents for both Architects and CMc. The steps needed to seek concurrence along with the required documents are attached or identified in this document.
STEP 1 - Steps for selecting an Architect:
If an Architect has been selected, provide a summary of the selection process. The summary should include: a) list of firms contacted, b) list of firms selected for interviews and c) a statement on why the firm was chosen over the other firms. If several firms were not evaluated, explain why in detail.
Or
If an Architect has not been selected, seek out at least three Architect firms and request qualifications. Interview several firms and submit the following to RD to review: a) list of firms contacted, b) list of firms selected for interviews and c) a statement on why the firm selected was chosen over the other firms.
The Iowa RD approved Architect Agreement for use with a CMc is AIA Document B133-2014, “Standard Form of Agreement Between Owner and Architect” and RD Guide 27 Attachment 4.
STEP 2 - Steps for selecting a CMc:
Prepare a Request for Proposal (RFP) and Scoresheet to rank the proposals. A sample RFP is included in this document. The Owner will send the RFP directly to CMc firms. The list of firms directly contacted will be included in the documentation to RD. Multiple firms must be contacted.
After the proposals are received, the CMc selection committee will review all proposals and select the best firms to interview.
Interview the best firms, complete the Scoresheet and make a recommendation to select a firm.
If the selected firm fees are above other qualified firms’ fees, including firms not selected for an interview, provide a detailed explanation explaining the benefit of the selected firm over all the other qualified firms.
STEP 3 - Documentation to submit to RD for review and concurrence of a CMc:
The Owner will prepare the CMc request addressing items A-F below. All of this information must be submitted in one package to RD, preferrably by email. RD will review the request for completeness and submit it to the RD National Office for review and concurrence. The review process may take several weeks to complete.
A) The Owner shall submit a written request to use a CMc with a description of the proposed method to RD. The request shall document why this method is advantageous to the Owner and RD.
B) Documentation of selection process of the selected Architect and CMc, see items in Steps 1 & 2 above.
C) Provide a detailing listing and estimated cost for the entire project which includes Architect, CMc, Environmental, Equipment, Furnishings, Land/Rights, Legal; Professional fees, and all other costs to complete the project and are necessary to properly operate the facility.
Architect fees: Provide a summary of the proposed Architect fees. Fees should not be based as a percent of the work, instead fees can be a lump sum or a cost not to exceed amount. Show Basic Services 11.1, Additional Services 11.2, and Reimbursable expenses 11.10. A full copy of the Architect Agreement is not required at this time.
CMc fees: Provide a summary of the selected CMc fees as lump sum or cost not to exceed amounts for these four areas: Preconstruction services, Personnel, Fee (profit and overhead), and General Conditions and Reimbursables. A full copy of the CMc Agreement is not needed at this time.
D) Explain or define how inspection services will be performed. Detail what the Architect will do, and explain third party inspector(s) roles. The CMc cannot perform inspections for RD purposes. Provide a sample listing of stage and component inspections and who is proposed to complete the inspections. A sample inspection list is provide in this document.
E) Provide a Preliminary Architectural Report prepared in accordance with Guide 6 of RD Instructions 1942-A.
F) Provide an Owner's attorney's opinion and comments regarding the legal adequacy of the proposed Contract Documents and evidence that the Owner has the legal authority to enter into and fulfill the contract.
After the RD National Office concurs in the CMc process, RD will provide a written concurrence to the Owner. If you have any questions on the process, please contact the RD Area Specialist.
Note on inspections:
RD requires full time inspection on all projects by independent parties from the Contractor performing the work. RD requires that qualified people perform the inspections. RD will review the resumes and concur in all inspectors. In order to adequately review the Architect and CMc Agreements, RD needs to understand the role of both during the construction phase. The Architect will be performing some of the inspections and some of the inspections will be completed by 3rd party independent firms. A CMc will not meet RD’s requirements for an independent inspector. We request that the Architect develop a list of systems to be inspected and a suggested list of who will be doing the inspections. Attached is an example of a previous RD hospital project.
The Architect Agreement requires the Architect to attend monthly progress meetings as part of Basic Services. RD will not concur in this as the only inspections the Architect preforms for CMc projects.
Grading and Site Prep Inspections - XXX Consultants, Inc.
Grading and Excavation Operations
Fill and Backfill Placement, daily
Earthwork Compaction and Subgrades Inspection and Testing, daily during placement.
Verification of Soil Bearing Capacities
Structural Steel Inspections - YYY Consultants, Inc. Weekly, as needed.
Material Verification of Steel Deck
Metal Deck Weld Inspection
High Strength Bolting Connections within the Roof Framing
Brace Frame Welded Connections
Joist End Bearing Field welded Connections
Steel Frame Inspection – BBB Engineers
Concrete Testing - XXX Consultants, Inc. Daily, during all pours.
Reinforcing Steel Inspections of slabs, concrete walls and grade beams
Verification of Concrete Placement and Method
Testing of Concrete Samples for Strength, Slump, and Air Content
Moisture Testing of Concrete by Barrier One or Equal Firm
Interior Metal Framing, Drywall, Casework, Flooring and Interior Finishes – Architect
Periodic Site Visits (weekly inspections during peak construction periods) and Final Inspections - conformance to specifications and approved submittals
Exterior Skin, and Roofing – Architect
Periodic Site Visits and Final Inspections - conformance to specifications and approved submittals
Plumbing and Mechanical – VVV Engineers and Commissioning Firm to be determined. Inspections prior to covering up; when testing by other occurs.
Periodic Site Visits and Final Inspection
Conformance to specifications and approved submittals
Commissioning HVAC Systems by Independent Commissioning Firm TBD
- Minimal VAV's tested, air handlers, and test and balance report
Water Sample Testing and Report– Independent Co. TBD
Backflow Certification – Independent Co. TBD
Medical Gas Certification – MMM Medical or Independent Co. TBD
Boiler Inspection Report – State of Iowa
Fire Sprinkler Testing – Firm TBD
Ansul System inspection - Independent Co. TBD
Electrical – ZZZ Engineers, State Inspections, and Firms to Be Determined. Inspections times____
Periodic Site Visits and Final Inspection
Conformance to specifications and approved submittals
Nurse Call Testing/inspection Report– Firm TBD
Generator Test Report – Firm TBD
Automatic Transfer Switch Test Report – Firm TBD
Grounding Testing –Firm TBD
State of Iowa Inspections
Miscellaneous Inspections
Iowa Food Establishment Inspection – State of Iowa
Life Safety inspection – State of Iowa Fire Marshal
Physicists Inspection of Lead Shielding – Hospital's Physicists
RF and Magnetic Shielding Test Report – Firm TBD
AIA Owner-Architect Agreement for CMc
RD Guide 27 Attachment 17
Page 1 of 7
The standard Architect Agreement form to use is AIA B133-2014, Standard Form of Agreement Between Owner and Architect, Construction Manager as Constructor Edition.
Notes: RD does not allow fees to be shown as a percent, a lump sum amount must be shown.
RD does not allow a limit of liability clause to be added.
The following are RD required modifications the AIA document. These modifications can be attached to or typed directly into the AIA document.
Attach forms AD-1048 and RD 1940-Q to the Agreement.
ATTACHMENT TO AIA DOCUMENT B133-2014 Standard Form of Agreement Between Owner and Architect, Construction Manager as a Constructor Edition.
The provisions of this Attachment shall delete, modify and supplement the provisions contained in the "Standard Form of Agreement Between Owner and Architect, Construction Manager as a Constructor Edition,” AIA B133-2014. The provisions contained in this Attachment will supersede any conflicting provisions of the AIA Document. The term "Agency,” as used in this Attachment, shall mean the United States of America, acting through the United States Department of Agriculture.
Article 1, INITIAL INFORMATION
Under paragraph 1.1.5, delete the second agreement option listed.
Article 2, Architect’s Responsibilities
Delete the second sentence from paragraph 2.6.
ARTICLE 3, SCOPE OF ARCHITECT’S BASIC SERVICES
Add the following subparagraph to paragraph 3.1:
3.1.9 The Architect shall prepare a Preliminary Architectural Report (PAR) as outlined in RD Instruction 1942-A Guide 6 “Preliminary Architectural Feasibility Report”.
Subparagraph 3.3.5, subparagraph 3.4.1 and subparagraph 3.5.1, add the words "and concurrence by the Agency" after for “Owner’s approval".
Add the following subparagraphs:
3.3.7.1 The Architect shall provide the Owner with the appropriate documentation showing the Schematic Design and the estimated Project cost to the Owner to seek the concurrence of the Agency. When the Owner has accepted and the Agency has concurred on the Schematic Design studies and estimated Project cost, the project Architect may be authorized to proceed with the Design Development Documents. The Architect shall attend conferences with the Owner, representatives of the Agency and other interested parties as may be reasonably necessary.
AIA Owner-Architect Agreement for CMc
RD Guide 27 Attachment 17
Page 2
3.5 CONSTRUCTION DOCUMENTS PHASE SERVICES
Add the following subparagraph to paragraph 3.5.5
3.5.5.1 The Architect shall provide 6 sets of Construction Documents for use by the Owner, the Agency and the appropriate Federal, State and local agencies from whom approval of the Project must be obtained. The reproduction cost of such Construction Documents shall be included in the compensation paid to the Architect, notwithstanding subparagraph 11.8.1. The Owner shall obtain Agency concurrence with the Construction Documents, estimated project cost, and authorization to proceed in writing prior to the owner’s acceptance of the Construction Manager’s Guaranteed Maximum Price.
3.6 CONSTRUCTION PHASE SERVICES
Add the following to subparagraph 3.6.1.1 after the words "Contract for Construction": "and the conditions of RD Attachment to AIA Document A133/CMc-2009, Owner Construction Manager Agreement, and RD Guide 27, Attachment 4 to the General Conditions of the Contract for Construction."
Delete the following words from subparagraph 3.6.1.2 after the word, "terminates": "on the date the Architect issues the final Certificate for Payment" and substitute the words "at the expiration of the period of correction of the Work described in the Contract for Construction."
Delete the first sentence of subparagraph 3.6.1.3 and substitute the following:
3.6.1.3 The Architect shall be a representative of and shall advise and consult with the Owner during construction until final payment to the Contractor is paid, and at the Owner's direction during the period of correction of the Work described in the Contract for Construction. The Architect shall furnish architectural services and consultations necessary to correct minor construction defects encountered during such correction period. The Architect shall assist the Owner in performing a review of the Project during the 11th month after the date of substantial completion. Such services shall be furnished without additional charge except for travel and subsistence costs.
Add the following subparagraphs to paragraph 3.6.1
3.6.1.4 Upon award of the construction contract, the Architect shall furnish to the Owner 5 sets of Construction Contract Documents for execution. The costs of these sets shall be included in the compensation to the Architect notwithstanding subparagraph 11.8.1.
3.6.1.5 The Architect shall participate in the Preconstruction Conference and shall advise and consult with the Owner and the Agency.
Subparagraph 3.6.2.1 following the first sentence add, “Such visits to the site shall be documented in writing on inspection report forms acceptable to the Owner and the Agency. Copies shall be furnished to the Owner, Contractor and the Agency.”
Subparagraph 3.6.2.5 after the words "AIA Document A201-2017", add: "with RD Guide 27, Attachment 4,"
AIA Owner-Architect Agreement for CMc
RD Guide 27 Attachment 17
Page 3
Add the following subparagraph to paragraph 3.6.2:
3.6.2.6 The Architect shall advise the Owner and the Agency of required tests, inspections and test results; shall furnish coordination of such tests and inspections; and shall advise the Owner and the Agency of the results of same. Copies of tests results shall be furnished upon request to the Owner, and the Agency.
Add the following subparagraph to paragraph 3.6.3:
3.6.3.4 The Architect shall obtain Agency concurrence on all Certificates of Payment before payment is made.
Modify subparagraph 3.6.5.1 as follows:
Add the following to the end of the subparagraph: Preparation of Change Orders which do not substantially affect the Project shall be included in the compensation computed in paragraph 11.8.1. The Owner, with the assistance of the Architect, shall obtain Agency concurrence in writing for all change orders prior to the performance of the Work.
Add the following subparagraph 3.6.5.3:
3.6.5.3 Any details that are not described in the Design Development Documents will be up to the Architect and the CMc to work out within the established GMP amount and without a change order cost paid by the Owner. Inferred items will not be considered a change order unless they are specifically spelled out in the CMc comments in the GMP Agreement. In addition any changes in the final plans due to errors or omissions shall be responsibility of the CMc and Architect to work out. Contingency will be built into the GMP and may be used for any missing items or errors or omissions. If there is a project scope change requested by the Owner or if unknown/undiscovered conditions are encountered during construction those costs will be the responsibility of the Owner.
Delete subparagraphs 3.6.6.1, 3.6.6.2, 3.6.6.3 and 3.6.6.4 and substitute the following:
3.6.6.1 The Architect shall conduct an inspection prior to the issuance of the Certificate of Substantial Completion and shall submit a written report of work to be completed to the Owner, the Agency and the Contractor prior to final acceptance. The Architect shall notify the Agency about inspection allowing reasonable time for the Agency's representative to attend. Such services shall be coordinated with the Agency. Prior to submitting the final Certificate for Payment, the Architect shall; 1) conduct an inspection to determine compliance with the requirements of the Contract Documents, and 2) receive and forward to the Owner, for the Owner's review and records, written warranties and related documents required by the Contract Documents and assembled by the Contractor.
ARTICLE 4, ADDITIONAL SERVICES
Insert the word “Architect” under the heading “Responsibility” for line items 4.1.12, 4.1.13, and 4.1.16 in the chart.
Article 4.2: Add the following subparagraphs to paragraph 4.2.
AIA Owner-Architect Agreement for CMc
RD Guide 27 Attachment 17
Page 4
4.2 (a) The Architect shall provide a detailed cost estimate based on Construction Contract Documents. The estimate shall show a breakdown of the project cost in accordance with Rural Development requirements and procedures.
4.2 (b) The selection and compensation of the Project Representative, if required, shall be concurred in by the Agency.
4.2 (c) 2 sets of Record Drawings shall be provided to the Owner. The costs of these sets shall be included in the compensation to the Architect not withstanding Subparagraph 11.8.1.
Article 4.3.2. Delete items .3 and .6
ARTICLE 5, OWNER’S RESPONSIBILITIES
Add the following subparagraph:
5.15 Owner shall provide Agency design and construction document regulations and guides to the Architect, upon request. The Owner shall provide information on requirements and procedures of the Agency.
ARTICLE 6, COST OF THE WORK
Add the following subparagraph:
6.8 The Architect shall consult with the Agency Architect or Engineer about the Agency’s requirements and procedures.
ARTICLE 8, CLAIMS AND DISPUTES
Delete subparagraph 8.1.2 in its entirety.
Subparagraph 8.2.2: Delete the words in the first sentence "unless the parties mutually agree otherwise" and add the words "if the parties mutually agree".
ARTICLE 9, TERMINATION OR SUSPENSION
Subparagraph 9.2, Delete the second sentence and add the following:
When the Project is resumed, the Architect's compensation may be equitably adjusted, as mutually agreed, to provide for expenses incurred in the interruption and resumption of the Architect's services.
Subparagraph 9.7, after "Termination Expenses" insert the words "as mutually agreed", and delete the words “plus an amount for the Architect’s anticipated profit on the value of the services not performed by the Architect”.
ARTICLE 10, MISCELLANEOUS PROVISIONS
AIA Owner-Architect Agreement for CMc
RD Guide 27 Attachment 17
Page 5
Delete subparagraph 10.1 and substitute the following:
10.1 This Agreement shall be governed by the laws of the Project location.
Subparagraph 10.2 after the words "Contract for Construction", add the following "with RD Guide 27, Attachment 4,"
Add the following subparagraphs:
10.9: This Agreement and any amendments to this Agreement shall not be in full force and effect until concurred with in writing by the Agency State Director or the State Director's delegate. Such concurrence shall be evidenced by the signature of such a representative of the Agency in the space provided at the end of this Agreement.
10.10: If applicable, the Architect shall comply with section 319 of Public Law 101-121, as supplemented by the Department of Agriculture regulations (7 C.F.R. part 3018). This statute pertains to restrictions on lobbying and applies to the recipients of contracts and subcontracts that exceed $100,000 at any tier under a Federal loan that exceeds $150,000 or a Federal grant that exceeds $100,000. If applicable, the Architect must complete a certification form on lobbying activities related to a specific Federal loan or grant that is a funding source for this Contract. The certification and disclosure forms shall be provided by the Owner. Form 1940-Q.
10.11: The Architect agrees to abide by the requirements under Executive Order 12549, which pertains to the debarment or suspension of a person from participating in a Federal program or activity. If the total compensation described in Article 1.5 exceeds $25,000, the Architect shall complete the relevant certification form provided by the Owner. Form AD1048.
10.12: The Architect shall comply with Executive Order 11246, “Equal Employment Opportunity”, as amended by Executive Order 11375, and as supplemented by Department of Labor Regulations at 41 CFR 60. If the total compensation described in Article 1.5 exceeds $10,000, the Architect shall complete Form RD 400-6.
ARTICLE 11, COMPENSATION
Delete subparagraph 11.8.2 in its entirety.
Subparagraph 11.10.4: Add the words "or representatives of the United States of America" after the word "Owner".
Add the following subparagraph to paragraph 11.10:
11.10.5: The Architect shall provide a detailed cost estimate for Reimbursable Expenses as defined in subparagraph 11.8.1, which shall be attached and made a part of this Agreement. The cost estimate must be approved in writing by the Owner and shall be concurred with in writing by the Agency before the services are rendered. The billings for reimbursable services shall not exceed the budgeted amount without prior approval of the Owner with the concurrence of the Agency. The Agency may not concur in requests for payments which exceed the budgeted amount unless it is established that funds are available for such expenditures.
AIA Owner-Architect Agreement for CMc
RD Guide 27 Attachment 17
Page 6
ARTICLE 12, SPECIAL TERMS AND CONDITIONS
Add the following subparagraph 12.1:
12.1 This Agreement is modified and supplemented by AIA Owner-Architect Agreement RD Guide 27, Attachment 17.
ARTICLE 13, SCOPE OF THE AGREEMENT
Subparagraph 13.1: In the second sentence delete the word "both" and add the words "and Agency" after the word “Architect”.
AIA Owner-Architect Agreement for CMc
RD Guide 27 Attachment 17
Page 7
SIGNATURE BLOCK:
Delete the signature block on the last page of this Agreement and substitute the signature block below:
IN WITNESS WHEREOF, the parties hereto have executed, or caused to be executed by their duly authorized officials, this Agreement in duplicate on the respective dates indicated below.
OWNER:
ATTEST: __________________________ By ________________________________
Type Name ________________________ Type Name _________________________
Title ____________________________ Title _____________________________
Date _____________________________ Date ______________________________
ARCHITECT:
ATTEST: __________________________ By ________________________________
Type Name ________________________ Type Name _________________________
Title ____________________________ Title _____________________________
Date _____________________________ Date ______________________________
The United States of America, as potential lender or insurer of funds to defray the costs of this agreement and without liability for any payments thereunder, hereby concurs in the form, content and the execution of this agreement.
U.S. Department of Agriculture
Rural Development
Rural Housing Service
By ________________________________
Type Name _________________________
Title _____________________________
Date ______________________________
Request for Proposal
Construction Manager as Constructor
To be modified to fit specific project needs. “Remove this note”
A. executive summary
Your Company is invited to submit a Proposal for Construction Manage as Constructor (CMc). The request for proposal is part of a competitive selection process to engage a CMc firm to provide services for the construction of XXXXXX.
ABC has procured the services of Architect to provide professional services for the design of this project. A copy of the most recent floor plan, and preliminary site plan are included as Attachment A.
ABC has (submitted an application for) (or secured) funding this project with the USDA-Rural Development. Commencement of this project is dependent on the timing of securing financing. Owner is hopeful for a construction start date of XXXX.
B. Owner
Owners name.
C. PROJECT LOCATION
XXXX
D. Scope of project
XXXX
E. project delivery method
It is intended that this project will be delivered using a CMc. The form of contract for CMc Services will be A133/CMc-2009, Standard Form of Agreement Between Owner and Construction Manager where the Construction Manager is also the Constructor with USDA Rural Development attachments. Owner will hold the project team’s contracts (including the CMc and Architect). The CMc will hold the subcontractors’ contracts. Construction Phase services will be at-risk via a guaranteed maximum price (GMP). Owner is budgeting $____________ million for the GMP. It is Owner’s expectation that the CMc will be able to deliver services, information, and benchmarking costs which will allow Owner to make timely and informed decisions in a compressed schedule. It is anticipated that the CMc will deliver a final GMP to the Owner upon completion of the Construction Documents. 100% of any savings to the GMP will be returned to the Owner.
This will be an open-book, transparent process. The successful CMc will have the ability to self perform work, but only through a competitive bid process for the work. Any bidding event that includes a bid from the CMc for work they will self perform will require that sealed bids be received at the same time by the Owner from all bidding contractors.
F. project schedule milestones
• Send Out RFP for CMc Services XX
• Proposals for CMc Services Due XX
• Selection Committee Interviews XX*
• Notification of Selected CMc firm XX Contingent **
* Please reserve your calendar accordingly. It is a requirement that the key members of the team and the Project Superintendent be present at the interview.
** USDA Rural Development requests the CMc Agreement not be executed until after RD has concurred in the use of a CMc.
G. scope of services
Services are to be as outlined in the AIA A133-2009 and USDA RD attachment documents.
The CMc along with Owner and Architect will be a critical member of the project team. It is expected that the CMc provide input on constructability, quality of materials, schedule and cost prior to the completion of the design documents. The successful CMc will be responsible to drive the project quality, cost, and schedule to meet Owner needs.
The following is a discussion if any CM firm has worked with the Owner on this specific project.
CM firms develop relationships in the course of their business practices. Repeat projects from owners, or by building type, is the reward for a successful endeavor. The government does not want to prevent that relationship. However on government funded projects all CM firms should have an equal opportunity to be considered for the project. To do this the Owner needs to create a properly detailed RFP that describes the project and describes the selection process/criteria and any past involvement that other CM firms have had on this specific project with the Owner. Therefore if the Owner has had a CM firm work specifically on this project the information generated by this CM firm needs to be shared with others in this RFP. To do this the RFP must state the name of the CM firm and what was done. Here is an example:
XYZ was asked to develop a scoping cost estimate to assist the owner with a project feasibility study. XYZ developed a scoping cost estimate based on past experience with similar projects and generic high level discussions with the owner. The cost product is attached as Appendix A.
H. Request for Information
To properly evaluate each CMc firm please provide the following information using this outline as a template for your responses. If additional information is submitted, please include it separately from your official proposal. The Owner needs ______ hard copies of the proposal and email a PDF copy to __________________
Section 1.0
Background Information
• Company profile.
• Company capacity and projected volume of work.
• List company’s total construction dollar volume, over the past 3 years, by year.
• Company philosophy and core values.
• Company mission statement.
Section 2.0
Experience and Qualifications
• Provide five (5) profiles of projects your company has completed that are of similar size and complexity, where your company was the CMc “At Risk”. NOTE: Do not include multiple phase projects without noting size and scope of each phase. Include:
o Brief description of project and photo
o Size, e.g. square feet and scope
o Original contract construction costs and final contract construction costs
o Project delivery method
o Owner and contact information
o Completion date
o Architect/Engineer of record
• Describe your experience and knowledge of Iowa contractors, and the contractor market specific to this project area.ng with the office staff.
• Describe your company’s experience in working with state and local agencies applicable to this project.
Section 3.0
Office/Corporate Structure
• Provide a corporate organizational chart for your company, inclusive of any parent companies.
• List number of Project Managers and Principals.
Section 4.0
Project Team
• How will your firm propose to structure the project team to ensure a successful project?
• Provide a detailed project specific organizational chart indicating titles and responsibilities. Address such for both pre-construction and construction phase services.
• Include a resume and references for each specific individual that will be working on the project.
Section 5.0
Company Differentiation and Management of the Process
• Describe how your company will manage the design and construction process, including how pro-active and participative your firm will be during the programming, schematic design, design development phase, and construction of the project. Use the following items as an outline for you responses.
1. Programming and preliminary design.
2. Preconstruction Phase:
▪ Explain what Value Engineering services your firm can provide.
▪ Describe what your firm does when reviewing plans for constructability.
▪ Explain how detailed and accurate your schedules and cost projections are at the project stages of SD and DD – 50% - 75%, and final construction documents.
▪ Discuss when you will submit a GMP for the project.
3. Discuss your Bidding strategy.
4. Construction Phase. Discuss how your firm will coordinate the activities of the subcontractors in the following areas:
▪ Change Orders.
▪ Schedule Management.
▪ General Construction.
▪ Performance of work by subcontractors. Discuss your method of oversight of the work, and how you coordinate third party inspections.
▪ Safety program.
▪ Federally funded work performed for construction must allow open competition. Whether performed by the CMc or subs. The CMc Proposal must reveal to the owner the CMc’ s intent to self-perform any work so the competitive process is fair, open and free. If the CMc desires to self-perform work the CMc must submit a Bid to the Owner prior to receiving bids from subs for that work. The owner will review all Bids and has the option of accepting or rejecting the Bid by the CMc.
Some self-perform work by a CMc can be done without competition if said work is secondary or complementary to the project such as temp fencing, access, temp utilities, or other features that are not a part of the final project. The CMc must identify this work including a cost not to exceed amount in the Proposal. The work will be paid on an hourly basis with a cost not to exceed.
5. Discuss your Project Close-Out and Start-Up strategy.
Section 6.0
Bonding Requirements
• 100 % Performance and Payment Bonds are required to be provided by the CMc.
• Provide your present total and available bonding capacity, your bonding company, and its rating according to generally recognized rating services.
Section 7.0
Insurance
• Indicate your insurance coverage limits.
• Provide your current and historic (3 prior years) experience modifier rating for your Workers Compensation program.
• Provide your current and historic (3 prior years) general liability insurance cost on a
cost/$ thousand basis.
Section 8.0
Litigation
• Has your organization been involved in litigation within the past five years? If so, please describe and note the disposition of all cases.
Section 9.0
Construction Schedule
• Develop and submit a proposed construction schedule based off the aforementioned information.
• A complete set of construction documents (100% complete design) will need to be submitted to RD for review for any phase of work, prior to start of construction on that phase of work. RD will require a minimum of two weeks to review the documents.
Section 10.0
Construction Budget
• The GMP budget is maximum of $XXX million. What will your firm do to stay within this budget?
Section 11.0
Cost Proposal
▪ USDA Rural Development generally limits the total cost paid to the CMc to 2 - 7% of the cost of construction. Excluding bidding in specific Division of the work. Provide a detailed breakout of the following:
a. Pre-Construction Services:
▪ Your proposal for pre-construction services with a cost not to exceed.
▪ Your reimbursable itemized expenses stated as a total not-to-exceed cost.
Construction Services and fees:
▪ Clearly define and itemize all of your estimated cost of services as follows:
b. CMc personnel Cost. Identify the number of personnel and positions budgeted for this project (Full Time and Part Time, hourly rates). Show the cost for each position and the total lump sum amount for the project.
c. Number of full time and number of part time people.
d. CMc Fee (Profit and Overhead). The CMc fee for Profit and Overhead shall be a fixed lump sum amount set at the time the GMP is established. The lump sum fee shall only change for change orders requested by the Owner. The fee shall increase and decrease on the net change order amount. However the fee will not be reduced below the amount set at the time the GMP is established.
e. General Condition costs. Provide an itemized list of costs.
f. Bond and insurance costs.
▪ Specify what you will negotiate and set to be the markup and markdown on change order work for all subcontractors.
NOTE: RD will require that any details that are not described in the Design Development Documents will be up to the Architect and the CMc to work out within the established GMP amount and without a change order cost paid by the Owner. Inferred items will not be considered a change order cost that the Owner is responsible for unless they are specifically spelled out in the CMc comments in the GMP Agreement. In addition any changes in the final plans due to errors or omissions shall be responsibility of the CMc and Architect to work out. The contingency built into the GMP may be used for missing items, errors, or omissions. If there is a project scope change requested by the Owner or if unknown/undiscovered conditions are encountered during construction those costs will be the responsibility of the Owner.
NOTE: Owner, Architect, and the CMc need to have a detailed discussion about the design intent, including quality and quantity of the components and materials. Knowledge of the details needs to be clearly understood by all parties and is the key to a successful project. When the design development documents and the proposed GMP have been developed, a copy of AIA Document A133-2009 Exhibit A will be submitted to Rural Development for review. When the Owner, the Architect, the CMc, and RD agree to a GMP, RD will provide concurrence.
Section 12.0
Address these general questions:
(Owner to add in other questions here and remove this note)
I. Interviews
The CMc selection committee will include board members, administrative team members, and the Architect. The selection committee will review the proposals and select the most qualified firms to interview. The interviews will be scheduled for the week of XXXX.
Note: RD requires the applicant to interview at least 2 firms. Remove this note
ATTACHMENTS:
Appendix A: Project information.
Appendix B: RD Attachment to AIA Document A133/CMc-2009. Standard Form of Agreement Between Owner and Construction Manager where the Construction Manager is also the Constructor.
Appendix C: RD Attachment to AIA Document A201-2017, General Conditions of the Contract for Construction
Appendix D: RD Instruction 194O-Q, Exhibit A-I.
Appendix E: Compliance Statement, RD 400-6.
Appendix F - Certification Regarding Debarment, Suspension, Ineligibility and Voluntary Exclusion - Lower Tier Covered Transactions, AD-1048.
This is a sample score sheet. Each project will develop its own point system based on the specifics of the project. Location of the firm should not be a consideration.
The owner is not required to include this score sheet with the RFP or share the scores with the CMa firms.
|CMc Score Sheet |
| |RFP Item No.|Maximum Points per Category |Points Awarded the CMc |
|Background Information |1 | | |
|Experience References |2 | | |
|Office & Structure |3 | | |
|Project Team |4 | | |
|Management Process |5 | | |
|Bonding |6 | | |
|Insurance |7 | | |
|Litigation & Conflicts of Interest |8 | | |
|Construction Schedule |9 | | |
|GMP Construction Budget |10 | | |
|Preconstruction Service Fee |11a | | |
|CM Personnel Cost |11b | | |
|Number of People |11c | | |
|Full Time= Part Time= | | | |
|CM Fees Profit & Overhead |11d | | |
|CM General Conditions cost |11e | | |
|Bond Cost & Insurance Costs |11f | | |
|Total CM Fees (a-f) |11 | | |
|Owner Questions |12 | | |
|Interview |I | | |
|Score | |100 | |
Appendix A: Project information
Appendix B:
RD ATTACHMENT TO AIA DOCUMENT A133/CMc-2009 page 1 of 3
Standard Form of Agreement Between Owner and Construction Manager where the Construction Manager is also the Constructor (do not type this into the Agreement use as an attachment).
The provisions of this Attachment shall delete, modify, and supplement the provisions contained in the “Standard Form of Agreement Between Owner and Construction Manager where the Construction Manager is also the Constructor", AIA Document A133/CMc-2009 Edition. The provisions contained in these Modifications shall supersede any conflicting provisions of the AIA Document. The term "Agency", as used in these Modifications, shall mean the United States of America, acting through the United States Department of Agriculture.
ARTICLE 2, CONSTRUCTION MANAGER’S RESPONSIBILITIES
2.2.2 Add the words “and Agency” after the word ”architect” in subparagraph 2.2.2.
2.2.2 Add the following to end of subparagraph 2.2.2. “Any details that are not described in the Design Development Documents will be up to the Architect and the CMc to work out within the established GMP amount and without a change order cost paid by the Owner. Inferred items will not be considered a change order unless they are specifically spelled out in the CMc comments in the GMP Agreement. In addition any changes in the final plans due to errors or omissions shall be responsibility of the CMc and Architect to work out. The contingency built into the GMP may be used for missing items, errors, or omissions. If there is a project scope change requested by the Owner or if unknown/undiscovered conditions are encountered during construction those costs will be the responsibility of the Owner.”
2.2.5 Add the words “and Agency” after the word ”architect” in subparagraph 2.2.5.
2.2.6 Add the follow to the end of subparagraph 2.2.6. “The Guaranteed Maximum Price proposal shall not become effective until concurred in writing by the signature of a duly authorized representative of the Agency. The concurrence so evidenced by the Agency shall in no way commit the Agency to render financial assistance to the Owner and is without liability to the Agency for any payment thereunder, but in the event such assistance is provided, the concurrence shall signify the provisions of the Guaranteed Maximum Price proposal are consistent with Agency requirements.”
2.3.2.5 Add the word “monthly” after the word “conduct” in subparagraph 2.3.2.5.
ARTICLE 7, CONSTRUCTION PHASE
7.1.11 Add the following subparagraph to article 7.1:
7.1.11 The amount retained shall be 5% of the value of work. If the Owner and Architect determine that the Work is not proceeding satisfactorily, additional amounts may be retained, but in no event shall the total retainage be more than 10% of the value of Work completed.
7.2.2 Replace the word "seven" with the word "ten (10)" in the second sentence; and add the words, "using AIA Documents 702, 'Application and Certificate for Payment' or Form RD 1924-18, 'Partial Payment Estimate'," after "Certificate for Payment" in that sentence.
7.2.4 Replace the word "shall" with the word "may" in the first and second sentences of subparagraph 7.2.4.
7.2 Add the following subparagraph to article 7.2:
7.2.6 Amounts withheld from the final payment to cover any incomplete work are not considered retainage and shall not be paid to the Construction Manager until the work is actually completed and accepted by the owner. Such withholdings shall not be less than 200% of the estimated cost to complete the work.
RD ATTACHMENT TO AIA DOCUMENT A133/CMc-2009 page 2 of 3
ARTICLE 9, MISCELLANEOUS PROVISIONS
9.1.1 Replace the word "shall" with the word "may" in the first sentence of subparagraph 9.1.1.
ARTICLE 11, OTHER CONDITIONS AND SERVICES
Add the following paragraphs to article 11:
11.6 The date of Substantial Completion established by this contract is:
11.7 If the Work is not substantially complete on or before the date of Substantial Completion established in paragraph 11.1, or extension thereof granted by the Owner, the Construction Manager shall pay to the Owner liquidated damages in the sum of $________ for each calendar day of delay. Any sums that may be due the Owner as liquidated damages may be deducted from any monies due or to become due the Constructor under the Contract or may be collected from the Constructor's surety.
11.8 This Agreement shall not become effective until concurred with in writing by the Agency. Such concurrence shall be evidenced by the signature of a duly authorized representative of the Agency in the space provided at the end of the Agency Attachment to this Agreement.
11.9 The following Documents shall be included:
AIA A133/CMc-2009
RD Attachment to AIA Document A133/CMc-2009 (this document).
AIA A201-2017, General Conditions of the Contract for Construction.
RD Guide 27, Attachment 4, Attachment to AIA A201-2017.
Compliance Statement (Form RD 400-6).
Certificate of Insurance.
Payment Bond. *
Performance Bond. *
Certification Regarding Debarment, Suspension, Ineligibility and Voluntary Exclusion - Lower Tier Covered Transactions (Form AD 1048).
Disclosure of Lobbying Activities (Form SF-LLL) Certification for Contracts, Grants and Loans (RD Instruction 1940-Q, Exhibit A-1).
Payment Request, RD 1924-18. *
Contract Change Order Form, RD 1924-7. *
Project Sign. *
*These forms may be found on the Iowa RD web site under the buttom “Architect” at:
Article 12, SCOPE OF SERVICES
12.1 Add the following words “and concurred by the Agency.” at the end of the second sentence.
12.1 Add the following after the second sentence “This Agreement shall not become effective until concurred in writing by the signatures of a duly authorized representatives. The concurrence so evidenced by the Agency shall in no way commit the Agency to render financial assistance to the Owner and is without liability to the Agency for any payment thereunder, but in the event such assistance is provided, the concurrence shall signify the provisions of this Agreement are consistent with Agency requirements.”
12.2 The following signature block shall replace the signature block following paragraph
IN WITNESS WHEREOF, the parties hereto have executed, or caused to be executed by their duly authorized officials, this Agreement in duplicate on the respective dates indicated below:
RD ATTACHMENT TO AIA DOCUMENT A133/CMc-2009 page 3 of 3
OWNER:
ATTEST: ___________________________ By _______________________________
Type Name _________________________ Type Name ________________________
Title _____________________________ Title ____________________________
Date ______________________________ Date _______________
CONSTRUCTION MANAGER:
ATTEST: ___________________________ By _______________________________
Type Name _________________________ Type Name ________________________
Title _____________________________ Title ____________________________
Date ______________________________ Date _____________________________
CERTFICATE OF OWNER’S ATTORNEY
I, the undersigned, the duly authorized and acting legal representative of Owner do hereby certify as follows: I have examined the attached Contract, insurance certificate, performance and payment bonds and the manner of execution thereof, and I am of the opinion that each of the aforesaid documents is adequate and has been duly executed by the proper parties thereto acting through their duly authorized representatives; that said representatives have full power and authority to execute said agreements on behalf of the respective parties named thereon; and that the foregoing agreements constitute valid and legally binding obligations upon the parties executing the same in accordance with the terms, conditions, and provisions thereof.
Name ________________________________ Date _______________
AGENCY CONCURRENCE:
By ________________________________
Type Name _________________________
Title _____________________________
Date ______________________________
The concurrence so evidenced by the Agency shall in no way commit the Agency to render financial assistance to the Owner and is without liability to the Agency for any payment hereunder, but in the event such assistance is provided, the concurrence shall signify the provisions of this Agreement are consistent with Agency requirements.
Appendix C:
RD Guide 27
Attachment 4
Page 1 of 9
ATTACHMENT TO AIA DOCUMENT A201-2017, General Conditions of the Contract for Construction
The provisions of this attachment shall delete, modify and supplement the provisions contained in the "General Conditions of the Contract for Construction,” AIA Document A201-2017 Edition. The provisions contained in this attachment will supersede any conflicting provisions of the AIA Document. The term "Agency,” as used in this Attachment, shall mean the United States of America, acting through the United States Department of Agriculture.
ARTICLE 1, GENERAL PROVISIONS
Add the following subparagraph:
1.2.4 Concurrence of the Contract by the Agency is required before it is effective.
ARTICLE 2, OWNER
Delete subparagraph 2.2.5 and substitute the following:
2.2.5 The Contractor will be furnished, free of charge, 2 copies of the Drawings and Projects Manuals necessary for execution of the Work. Additional copies will be available from the Architect at the cost of reproduction and handling.
ARTICLE 4, ARCHITECT
Add the following to subparagraph 4.1.1:
The term "Architect" means the Architect, or the Engineer when the nature of the work is within the authority granted engineers by the State licensure law, or an authorized representative of the Architect or Engineer.
ARTICLE 5, SUBCONTRACTORS
Add the following to subparagraph 5.2.2:
The Contractor shall not contract with any party who is suspended or debarred by any Federal government agency from participating in Federally assisted construction projects or to whom the Owner or the Architect has made reasonable and timely objection.
RD Guide 27
Attachment 4
Page 2
ARTICLE 7, CHANGES IN THE WORK
Delete the words ", Construction Change Directive" from subparagraph 7.1.1.
Insert the words ", Agency " after the word "Owner,” and delete the words "; a Construction Change Directive requires agreement by the Owner and Architect and may or may not be agreed to by the Contractor" in subparagraph 7.1.2.
Delete the words "Construction Change Directive" from subparagraph 7.1.3.
Delete subparagraph 7.2.1 and substitute the following:
7.2.1 A Change Order is a written order to the Contractor utilizing Form RD 1924-7, "Contract Change Order". It is issued after the execution of the Contract, authorizing a change in the Work or an adjustment in the Contract Sum or the Contract Time. The Contract Sum and the Contract Time may be changed only by Change Order. The Contractor's signing of a Change Order indicates complete agreement therein.
Add subparagraph 7.2.2:
7.2.2 Methods used in determining adjustments to the Contract Sum may include any of the following:
.1 Mutual acceptance of a lump sum properly itemized and supported by sufficient substantiating data to permit evaluating.
.2 Unit prices stated in the Contract Documents or subsequently agreed upon.
Add the following sentence to paragraph 7.3: “A Construction Change Directive may be used only for a change in response to an emergency as described in paragraph 10.4.
ARTICLE 8, TIME
Add the following subparagraphs:
8.2.4 The Notice to Proceed shall be issued within twenty (20) calendar days of the execution of the Agreement by the Owner. Should there be reasons why the Notice to Proceed cannot be issued within such period, the time may be extended by mutual agreement of the Owner and Contractor, with the concurrence of the Agency. If the Notice to Proceed has not been issued within the twenty (20) calendar day period or within the period mutually agreed, the Contractor may terminate the Agreement without further liability on the part of either party.
8.3.4 As outlined in Article 3 of the Agreement, the Contractor agrees to pay liquidated damages to the Owner for each calendar day the Contractor shall be in default.
RD Guide 27
Attachment 4
Page 3
ARTICLE 9, PAYMENTS AND COMPLETION
Delete clause 9.3.1.1 and substitute the following:
9.3.1.1 Work performed and materials supplied under a Change Order may be included for payment only after the Change Order has been approved by all appropriate parties, including the Agency.
Add the words ", Form RD 1924-18, 'Partial Payment Estimate'," after "Certificate for Payment" in subparagraph 9.4.1.
Add the following subparagraph:
9.6.8 No progress payments will be made that deplete the retainage, nor place in escrow any funds that are required for retainage, nor invest the retainage for the benefit of the Contractor. Retainage will not be adjusted until after construction is substantially complete.
Replace the word "seven" with the words "fifteen (15)" in the first sentence, third line of subparagraph 9.7.
Delete subparagraph 9.8.5, after the first sentence, and substitute the following:
9.8.5 When the Work has been substantially completed, except for Work which cannot be completed because of weather conditions, lack of materials or other reasons, which, in the judgment of the Owner, are valid reasons for non-completion, the Owner may make additional payments, retaining at all times an amount sufficient to cover the estimated cost of the Work still to be completed. Provide a copy of the Certificate to the Agency.
Delete subparagraphs 9.9.1 through 9.9.3 and substitute the following:
9.9.1 The Contractor agrees to the use and occupancy of a portion or unit of the Project before formal acceptance by the Owner under the following conditions:
.1 A “Certificate of Substantial Completion” shall be prepared and executed as provided in subparagraph 9.8.4, except that when, in the opinion of the Architect, the Contractor is chargeable with unwarranted delay in completing the Work or other Contract requirements, the signature of the Contractor will not be required. The Certificate of Substantial Completion shall be accompanied by a written endorsement of the Contractor's insurance carrier and surety permitting occupancy by the Owner during the remaining period of the Project Work. Occupancy and use by the Owner shall not commence until authorized by public authorities having jurisdiction over the Work.
RD Guide 27
Attachment 4
Page 4
.2 Occupancy by the Owner shall not be construed by the Contractor as being an acceptance of that part of the Project to be occupied.
.3 The Contractor shall not be held responsible for any damage to the occupied part of the Project resulting from the Owner's occupancy.
.4 Occupancy by the Owner shall not be deemed to constitute a waiver of existing claims in behalf of the Owner or Contractor against each other.
.5 If the Project consists of more than one building, and one of the buildings is to be occupied, the Owner, prior to occupancy of that building, shall secure permanent property insurance on the building to be occupied and necessary permits which may be required for use and occupancy.
9.9.2 With the exception of clause 9.9.1.5, use and occupancy by the Owner prior to Project acceptance does not relieve the Contractor of responsibility to maintain all insurance and bonds required of the Contractor under the Contract Documents until the Project is completed and accepted by the Owner.
Delete the second and third sentences of subparagraph 9.10.2.
ARTICLE 11, INSURANCE AND BONDS
Replace the words "the Contract Documents" with the words "subparagraph 11.1.5" in the first sentence of subparagraph 11.1.2.
Add the following subparagraph:
11.1.5. Insurance shall be:
.1 Written with a limit of liability of not less than $_____________ for all damages arising out of bodily injury, including death, at any time resulting therefrom, sustained by any one person in any one accident; and a limit of liability of not less than $___________ aggregate.
For any such damages sustained by two or more persons in any one accident. Insurance shall be written with a limit of liability of not less than $____________ for all property damage sustained by any one person in any one accident; and a limit of liability of not less than $__________ aggregate for any such damage sustained by two or more persons in any one accident, or
.2 Written with a combined bodily injury and damage liability of not less than $____________ per occurrence; and with an aggregate of not less than $____________ per occurrence.
RD Guide 27
Attachment 4
Page 5
Modify the first sentence of subparagraph 11.3.1 as follows:
11.3.1 Delete “Unless otherwise provided, the Owner” and substitute “The Contractor”.
Add the following sentences to the end of subparagraph 11.3.1
The policy shall name as the insured the Contractor and the Owner. If the Owner is damaged by the failure of the Contractor to purchase and maintain such insurance without so notifying the Owner in writing, then the Contractor shall bear all reasonable costs attributable thereto.
Insert the word "Owner" after the words "protect the interests of the" in the second sentence of subparagraph 11.3.1.2.
Add the following sentence to the end of subparagraph 11.3.6:
The provisions of this subparagraph shall apply to the Contractor if the Contractor purchases and maintains said insurance coverage.
Delete subparagraph 11.3.7 in its entirety.
Delete subparagraph 11.4.1 and substitute the following:
11.4.1 The Contractor shall furnish the Owner bonds covering faithful performance of the Contract and payment of obligations arising thereunder within ten (10) calendar days after receipt of the Notice of Award. The surety company executing the bonds must hold a certificate of authority as an acceptable surety on Federal bonds as listed in Treasury Circular 570, and be authorized to transact business in the State where the Project is located. The bonds (using the forms included in the Bidding Documents) shall each be equal to the amount of the Contract Sum. The cost of these bonds shall be included in the Contract Sum
Add the following subparagraphs:
11.4.1.1 The Contractor shall require the attorney-in-fact who executes the required bonds on behalf of the surety to affix thereto a certified and current power of attorney.
11.4.1.2 If at any time a surety on any such bond is declared bankrupt or loses its right to do business in the State in which the work is to be performed or is removed from the list of surety companies accepted on Federal Bonds, the Contractor shall within ten (10) calendar days after notice from the Owner to do so, substitute an acceptable bond in such form and sum and signed by such other surety or sureties as may be satisfactory to the Owner. The premiums of such bond shall be paid by any Contractor. No further payment shall be deemed due nor shall be made until the new surety or sureties shall have furnished an acceptable bond to the Owner.
RD Guide 27
Attachment 4
Page 6
ARTICLE 13, MISCELLANEOUS PROVISIONS
Add the following paragraphs:
13.8 LANDS AND RIGHTS-OF WAY
13.8.1 Prior to the start of construction, the Owner shall obtain all lands and rights-of-way necessary for the execution and completion of work to be performed under this contract.
13.9 EQUAL OPPORTUNITY REQUIREMENTS
Non-discrimination in Employment by Federally Assisted Construction Contractors, by Executive Order 11246.
13.9.1 This section summarizes Executive Order 11246, which prohibits employment discrimination and requires employers holding non-exempt Federal contracts and subcontracts and federally-assisted construction contracts and subcontracts in excess of $10,000 to take affirmative action to ensure equal employment opportunity without regard to race, color, religion, sex, or national origin. The Executive Order requires, as a condition for the approval of any federally assisted construction contract, that the applicant incorporate nondiscrimination and affirmative action clauses into its non-exempt federally assisted construction contracts.
13.9.2 Executive Order 11246, is administered and enforced by the Office of Federal Contract Compliance Programs (OFCCP), an agency in the U.S. Department of Labor's Employment Standards Administration. OFCCP has issued regulations at 41 CFR chapter 60 implementing the Executive Order. The regulations at 41 CFR part 60-4 establish the procedures which the Agency, as an administering agency, must follow when making grants, contracts, loans, insurance or guarantees involving federally assisted construction which is not exempt from the requirements of Executive Order 11246. The regulations which apply to Federal or federally assisted construction contractors also are published at 41 CFR part 60-4.
13.9.3 OFCCP has established numerical goals for minority and female utilization in construction work. The goals are expressed in percentage terms for the contractor's aggregate workforce in each trade. OFCCP has set goals for minority utilization based on the percentage of minorities in the civilian labor force in the relevant area. There is a single nationwide goal of 6.9 percent for utilization of women. The goals apply to all construction work in the covered geographic area, whether or not it is federal, federally assisted or non-federal. A notice advises bidders of the applicable goals for the area where the project is to be located.
RD Guide 27
Attachment 4
Page 7
13.9.4 Application. This section applies to all of a construction contractor's or subcontractor's employees who are engaged in on-site construction including those construction employees who work on a non-Federal or non-Federally assisted construction site.
13.9.4.1 Agency officials will notify the appropriate Regional Director of OFCCP that an Agency financed construction contract has been awarded, and that the equal opportunity clauses are included in the contract documents.
13.9.4.2 The Regional Director, OFCCP-DOL, will enforce the non-discrimination requirements of Executive Order 11246.
13.9.5 The prospective contractor or subcontractor must comply with the Immigration Reform and Control Act of 1986, by completing and retaining Form I-9, "Employment Eligibility Verification," for employees hired. This form is available from the Immigration and Naturalization Service, and Department of Justice.
13.9.6 The prospective contractor or subcontractor must submit Form RD 400-6, "Compliance Statement," to the applicant and an Agency official as part of the bid package, prior to any contract bid negotiations and comply with the Executive Order 11246 as stated in the contract documents.
13.10 STATUTES
13.10.1 The Contractor and each Subcontractor shall comply with the following statutes (and with regulations issued pursuant thereto, which are incorporated herein by reference):
13.10.1.1 Copeland Anti-Kickback Act (18 U.S.C. 874) as supplemented in Department of Labor regulations (29 CFR part 3). This Act provides that each Contractor shall be prohibited from inducing, by any means, any person in connection with construction to give up any part of the compensation to which the person is otherwise entitled.
13.10.1.2 Clean Air Act (42 U.S.C. 7414), section 114, and Water Pollution Control Act (33 U.S.C. 1813), section 308. Under Executive Order 11738 and Environmental Protection Agency (EPA) regulations 40 C.F.R. part 15, all Contracts in excess of $100,000 are required to comply with these Acts. The Acts require the Contractor to:
.1 Notify the Owner of the receipt of any communication from EPA indicating that a facility to be utilized in the performance of the Contract is under consideration to be listed on the EPA list of Violating Facilities.
.2 Certify that any facility to be utilized in the performance of any nonexempt Contractor or Subcontractor is not listed on the EPA list of Violating Facilities as of the date of the Contract Award.
.3 Include or cause to be included the above criteria and requirements of paragraphs .1 and .2 in every nonexempt subcontract, and that the Contractor will take such action as the Government may direct as a means of enforcing such provisions.
RD Guide 27
Attachment 4
Page 8
13.10.1.3 Restrictions on Lobbying (Public Law 101-121, section 319) as supplemented in Department of Agriculture regulations (7 CFR part 3018). This statute applies to the recipients of contracts or subcontracts that exceed $100,000 at any tier under a Federal loan that exceeds $150,000 or a Federal grant that exceeds $100,000. If applicable, the Contractor must complete a certification form on lobbying activities related to the specific Federal loan or grant that is a funding source for this contract. The certification and disclosure forms shall be provided by the Owner.
13.11 RECORDS
13.11.1 If the Contract is based on a negotiated Bid, the Owner, the Agency, the Comptroller General of the United States, or any of their duly authorized representatives, shall have access to any books, documents, papers, and records of the Contractor which are pertinent to a specific Federal loan program for the purpose of making audit, examination, excerpts, and transcriptions. The Contractor shall maintain records for at least three years after the Owner makes final payment and all other pending matters are closed.
13.12 ENVIRONMENTAL REQUIREMENTS
13.12.1 Mitigation Measures – The contractor shall comply with applicable mitigation measures established in the environmental assessment for the project. These may be obtained from the Agency representative.
13.12.2 The Contractor, when constructing a Project involving trenching, excavating, or other earth moving activity, shall comply with the following environmental constraints:
13.12.2.1 Endangered Species, Historic Preservation, Human Remains and Cultural Items, Hazardous Materials, and Paleontology – Any excavation or other earth moving activity by the Contractor that provides evidence of the presence of endangered or threatened species or their critical habitat, uncovers a historical or archaeological artifact, human remains or cultural items, hazardous materials, a fossil or other paleontological materials will require the Contractor to:
.1 Temporarily stop work;
.2 Provide immediate notice to the Architect and the Agency, and in the case of potentially hazardous materials, provide immediate notice to local first responders and take such measures as necessary to protect the public and workers;
.3 Take reasonable measures as necessary to protect the discovered materials or protected resource;
.4 Abide by such direction as provided by the Agency, or Agencies responsible for resource protection or hazardous materials management; and
.5 Resume work only upon notice from the Architect and the Agency.
RD Guide 27
Attachment 4
Page 9
13.12.3 Lead-Based Paint - The Contractor and Owner shall comply with applicable Agency requirements of the Lead-Based Paint Poisoning Prevention Act, as amended (42 U.S.C. 4821), and the Residential Lead-Based Paint Hazard Reduction Act of 1992 (42 U.S.C. 4851) for rehabilitation work on residential property built prior to 1978.
13.13 DEBARMENT AND SUSPENSION
13.13.1 The Contractor shall comply with the requirements of 7 CFR part 3017, which pertains to the debarment or suspension of a person from participating in a Federal program or activity.
ARTICLE 15 CLAIMS AND DISPUTES
Add the words "may be" after "on the parties but" in the last sentence of subparagraph 15.2.5.
Replace the word "shall" with the word "may" in the first sentence, first occurrence of subparagraph 15.3.2
15.4.1.2 The arbitrators will select a hearing location as close to the Owner's locale as possible.
o0o
Appendix D
RD Instruction 194O-Q
Exhibit A-I
CERTIFICATION FOR CONTRACTS, GRANTS AND LOANS
The undersigned certifies, to the best of his or her knowledge and belief, that:
1. No Federal appropriated funds have been paid or will be paid, by or on behalf of the undersigned, to any person for influencing or attempting to influence an officer or employee of any agency, a Member of Congress, an officer or employee of Congress, or an employee of a Member of Congress in connection with the awarding of any Federal contract, the making of any Federal grant or Federal loan, and the extension, continuation, renewal, amendment, or modification of any Federal contract, grant or loan.
2. If any funds other than Federal appropriated funds have been paid or will be paid to any person for influencing or attempting to influence an officer or employee of any agency, a Member of Congress, an officer or employee of Congress, or an employee of a Member of Congress in connection with this Federal contract, grant or loan, the undersigned shall complete and submit Standard Form - LLL, "Disclosure of Lobbying Activities," in accordance with its instructions.
3. The undersigned shall require that the language of this certification be included in the award documents for all subawards at all tiers (including contracts, subcontracts, and subgrants under grants and loans) and that all subrecipients shall certify and disclose accordingly.
This certification is a material representation of fact upon which reliance was placed when this transaction was made or entered into. Submission of this certification is a prerequisite for making or entering into this transaction imposed by section 1352, title 31, U.S. Code. Any person who fails to file the required certification shall be subject to a civil penalty of not less than $10,000 and not more than $100,000 for each such failure.
__________________________________ __________________________________
(name) (date)
__________________________________
(title)
oOo
(08-21-91) PN 171 (4-7-97) SPN 508
Rural Development Instruction 1940-Q
Exhibit A, page 16
6744 Federal Register/Vol. 55. No. 38/Monday, February 26, 1990/Rules and Regulations
INSTRUCTIONS FOR COMPLETION OF SF-LLL, DISCLOSURE OF LOBBYING ACTIVITIES
This disclosure form shall be completed by the reporting entity, whether subawardee or prime Federal recipient, at the initiation or receipt of a covered Federal action, or a material change to a previous filing, pursuant to title 31 U.S.C. section 1352. The filing of a form is required for each payment or agreement to make payment to any lobbying entity for influencing or attempting to influence an officer or employee of any agency, a Member of Congress, an officer or employee of Congress, or an employee of a Member of Congress in connection with a covered Federal action. Use the SF-LLL-A Continuation Sheet for additional information if the space on the form is inadequate. Complete all items that apply for both the initial filing and material change report. Refer to the implementing guidance published by the Office of Management and Budget for additional information.
1. Identify the type of covered Federal action for which lobbying activity is and/or has been secured to influence the outcome of a covered Federal action.
2. Identify the status of the covered Federal action.
3. Identify the appropriate classification of this report. If this a follow-up report caused by a material change to the information previously reported, enter the year and quarter in which the change occurred. Enter the date of the last previously submitted report by this reporting entity for this covered Federal action.
4. Enter the full name, address, city, state and zip code of the reporting entity. Include Congressional District, if known. Check the appropriate classification of the reporting entity that designates if it is, or expects to be, a prime or subaward recipient. Identify the tier of the subawardee e.g., the first subawardee of the prime is the 1st tier. Subawards include but are not limited to subcontracts, subgrants and contract awards under grants.
5. If the organizations filing the report in item 4 checks "Subawardee", then enter the full name, address, city, state and zip code of the prime Federal recipient. Include Congressional District, if known.
6. Enter the name of the Federal agency making the award or loan commitment. Include at least one organizational level below the agency name, if known. For example, Department of Transportation, United States Coast Guard.
7. Enter the Federal program name or description for the covered Federal action (item 1). If known, enter the full Catalog of Federal Domestic Assistance (CFDA) number for grants, cooperative agreements, loans, and loan commitments.
8. Enter the most appropriate Federal identifying number available for the Federal action identified in item 1 (e.g. Request for Proposal (PFP) number, Invitation for Bid (IFB) number, grant announcement number, the contract, grant, or loan award number, the application/proposal control number assigned by the Federal agency). Include prefixes, e.g., "RFP-DE-90-001."
9. For a covered Federal action where there has been an award or loan commitment by the Federal agency, enter the Federal amount of the award/loan commitment for the prime entity identified in item 4 or 5.
10. (a) Enter the full name, address, city, state and zip code of the lobbying entity engaged by the reporting entity in item 4 to
influence the covered Federal action.
(b) Enter the full names of the individual(s) performing services, and include full address if different from 10 (a). Enter Last Name, First Name, and Middle Initial (MI).
11. Enter the amount of compensation paid or reasonably expected to be paid by the reporting entity (item 4) to the lobbying entity (item 10). Indicate whether the payment has been made (actual) or will be made (planned). Check all boxes that apply. If this is a material change report, enter the cumulative amount of payment made or planned to be made.
12. Check the appropriate box(es). Check all boxes that apply. If payment is made through an in-kind contribution, specify the nature and value of the in-kind payment.
13. Check the appropriate box(es). Check all boxes that apply. If other, specify nature.
14. Provide a specific and detailed description of the services that the lobbyist has performed, or will be expected to perform, and the date(s) of any services rendered. Include all preparatory and related activity, not just time spent in actual contact with Federal officials. Identify the Federal official(s) or employee(s) contacted or the officer(s), employee(s), or Member(s) of Congress that were contacted.
15. Check whether or not a SF-LLL-A Continuation Sheet(s) is attached.
16. The certifying official shall sign and date the form, print his/her name, title, and telephone number.
Public reporting burden for this collection of information is estimated to average 30 minutes per response, including time for reviewing instructions, searching existing data sources, gathering and maintaining the data needed, and completing and reviewing the collection of information. Send comments regarding the burden estimate or any other aspect of this collection of information, including suggestions for reducing this burden, to the Office of Management and Budget, Paperwork Reduction Project (0348-0046), Washington, D.C. 20503.
Appendix E:
USDA Form Approved
Form RD 400-6 OMB No. 0575-0018
(Rev. 4/00, Page 1 of 2)
COMPLIANCE STATEMENT
This statement relates to a proposed contract with ________________________________
________________________________________________________________________
(Name of borrower or guarantee)
who expects to finance the contract with assistance from Rural Development, United States Department of Agriculture (whether by a loan, grant, loan insurance, guarantee, or other form of financial assistance.) I am the undersigned bidder or prospective contractor. I represent that:
1. I ( have ( have not, participated in a previous participated in a previous contract or subcontract subject to Executive Order 11246 (regarding equal employment opportunity) or a preceding similar Executive Order.
2. If I have participated in such a contract or subcontract, I ( have, ( have not, filed all compliance reports that have been required to file in connection with the contract or subcontract.
3. I ( have, ( have not previously had contracts subject to the written affirmative action programs requirements of the Secretary of Labor.
4. If I have participated in such a contract or subcontract, I ( have, ( have not developed and place on file at each establishment affirmative action programs as required by the rules and regulations of the Secretary of Labor.
I understand that if I have failed to file any compliance reports that have been required of me, I am not eligible and will not be eligible to have my bid considered or to enter into the proposed contract unless and until I make an arrangement regarding such reports that is satisfactory to either the RHS, RBS, RUS, or to the office where the reports are required to be filed.
I also certify that I do not maintain or provided for my employees any segregated facilities at any of my establishments, and that I do not permit my employees to perform their services at any locations, under my control, where segregated facilities are maintained. I certify further that I will not maintain or provide for my employees any segregated facilities at any of my establishments, and that I will not permit my employees to perform their services at any location, under my control, where segregated facilities are maintained. I agree that a breach of this certification is a violation of the Equal Opportunity clause in my contract. As used in this certification, the term “segregated facilities” means any waiting rooms, work areas, restrooms and wash rooms, restaurants and other eating areas, time clocks, locker rooms and other storage or dressing areas, parking lots, drinking fountains, recreation or entertainment areas, transportation, and housing facilities provided for employees which are segregated by explicit directive or are in fact segregated on the basis of race, creed color, or national origin, because of habit, local custom, or otherwise. I further agree that (except where I have obtained identical certifications for proposed subcontractors for specific time periods) I will obtain identical certifications from proposed subcontractors prior to the award of subcontracts exceeding $10,000 which are not exempt from the provisions of the Equal Employment Opportunity clause; that I will retain such certifications in my files; and that I will forward the following notice to such proposed subcontractors (except where the proposed subcontractors have submitted identical certifications for specific time periods): (See Reverse).
According to the Paperwork Reduction Act of 1995, an agency may not conduct or sponsor, and a person is not required to respond to a collection of information unless it displays a valid OMB control number. The valid OMB control number for this information collection is 0575-0018. The time required to complete this information collection is estimated to average 10 minutes per response, including the time for reviewing instructions, searching existing data sources, gathering and maintaining the data needed, and completing and reviewing the collection of information.
Position 6 RD 400-6(Rev. 4/00, Page 1)
USDA Form Approved
Form RD 400-6 OMB No. 0575-0018
(Rev. 4/00, Page 2 of 2)
NOTICE TO PROSPECTIVE SUBCONTRACTORS OF REQUIREMENTS FOR
CERTIFICATIONS OF NON-SEGREGATED FACILITIES
A certification of Non-segregated Facilities, as required by the May 9, 1967, order (32 F.R. 7439, May 19, 1967) on Elimination of Segregated Facilities, by the Secretary of Labor, must be submitted prior to the award of a subcontract exceeding $10,000 which is not exempt from the provisions of the Equal Opportunity clause. The certification may be submitted for each subcontract or for all subcontracts during a period (i.e. quarterly, semiannually, or annually).
NOTE: The penalty for making false statements in offers is prescribed in 18 U.S.C. 1001.
DATE _____________________________ ______________________________________
(Signature of Bidder or Prospective Contractor)
__________________________________
Address (including Zip Code)
According to the Paperwork Reduction Act of 1995, an agency may not conduct or sponsor, and a person is not required to respond to a collection of information unless it displays a valid OMB control number. The valid OMB control number for this information collection is 0575-0018. The time required to complete this information collection is estimated to average 10 minutes per response, including the time for reviewing instructions, searching existing data sources, gathering and maintaining the data needed, and completing and reviewing the collection of information.
Position 6 RD 400-6 (4/00)
Page 2
Appendix F
U. S. DEPARTMENT OF AGRICULTURE
_____________________________________________________________________
Certification Regarding Debarment, Suspension, Ineligibility
and Voluntary Exclusion - Lower Tier Covered Transactions
_____________________________________________________________________
This certification is required by the regulations implementing Executive Order 12549, Debarment and Suspension, 7 CFR Part 3017, Section 3017.510, Participants' responsibilities. The regulations were published as Part IV of the January 30, 1989, Federal Register (pages 4722-4733). Copies of the regulations may be obtained by contacting the Department of Agriculture agency with which this transaction originated.
(BEFORE COMPLETING CERTIFICATION, READ INSTRUCTIONS)
(1) The prospective lower tier participant certifies, by submission of this proposal, that neither it nor its principals is presently debarred, suspended, proposed for debarment, declared ineligible, or voluntarily excluded from participation in this transaction by any Federal department or agency.
(2) Where the prospective lower tier participant is unable to certify to any of the statements in this certification, such prospective participant shall attach an explanation to this proposal.
_____________________________________________________________________
Organization Name PR/Award Number or Project Name
_____________________________________________________________________
Name and Title of Authorized Representative(s)
_____________________________________________________________________
Signature(s) Date
FORM AD-1048 ( 1/92 )
U.S. GPO:1996-757-778/20107
INSTRUCTIONS FOR CERTIFICATION
1. By signing and submitting this form, the prospective lower tier participant is providing the certification set out on the reverse side in accordance with these instructions.
2. The certification in this clause is a material representation of fact upon which reliance was placed when this transaction was entered into. If it is later determined that the prospective lower tier participant knowingly rendered an erroneous certification, in addition to other remedies available to the Federal Government, the department or agency with which this transaction originated may pursue available remedies, including suspension and/or debarment.
3. The prospective lower tier participant shall provide immediate written notice to the person to which this proposal is submitted if at any time the prospective lower tier participant learns that its certification was erroneous when submitted or has become erroneous by reason of changed circumstances.
4. The terms "covered transaction," "debarred," "suspended," "ineligible," "lower tier covered transaction, " "participant," "person, " " primary covered transaction," "principal," "proposal," and "voluntarily exclude," as used in this clause, have the meanings set out in the Definitions and Coverage sections of rules implementing Executive Order 12549. You may contact the person to which this proposal is submitted for assistance in obtaining a copy of those regulations.
5. The prospective lower tier participant agrees by submitting this form that, should the proposed covered transaction be entered into, it shall not knowingly enter into any lower tier covered transaction with a person who is debarred, suspended, declared ineligible, or voluntarily excluded from participation in this covered transaction, unless authorized by the department or agency with which this transaction originated.
6. The prospective lower tier participant further agrees by submitting this form that it will include this clause titled "Certification Regarding Debarment, Suspension, Ineligibility and Voluntary Exclusion - Lower Tier Covered Transactions," without modification, in all lower tier covered transactions and in all solicitations for lower tier covered transactions.
7. A participant in a covered transaction may rely upon a certification of a prospective participant in a lower tier covered transaction that it is not debarred, suspended, ineligible, or voluntarily excluded from the covered transaction, unless it knows that the certification is erroneous . A participant may decide the method and frequency by which it determines the eligibility of its principals. Each participant may, but is not required to, check the Nonprocurement List.
8. Nothing contained in the foregoing shall be construed to require establishment of a system of records in order to render in good faith the certification required by this clause. The knowledge and information of a participant is not required to exceed that which is normally possessed by a prudent person in the ordinary course of business dealings.
9. Except for transactions authorized under paragraph 5 of these instructions, if a participant in a covered transaction knowingly enters into a lower tier covered transaction with a person who is suspended, debarred, ineligible, or voluntarily excluded from participation in this transaction, in addition to other remedies available to the Federal Government, the department or agency with which this transaction originated may pursue available remedies, including suspension and/or debarment.
Form AD-1048 (1/92)
................
................
In order to avoid copyright disputes, this page is only a partial summary.
To fulfill the demand for quickly locating and searching documents.
It is intelligent file search solution for home and business.
Related searches
- introduction to financial management pdf
- letter of introduction sample
- argumentative essay introduction examples
- how to start an essay introduction examples
- introduction to finance
- introduction to philosophy textbook
- introduction to philosophy pdf download
- introduction to philosophy ebook
- introduction to marketing student notes
- introduction to marketing notes
- introduction to information systems pdf
- introduction paragraph examples for essays